리모델링 사업의 고유 리스크 요인들로 인해, 리모델링 사업의 실패가 빈번하게 발생하고 있는 실정이며 특히 공기지연이 거의 대부분의 리모델링 프로젝트에서 발생하고 있는 실정이다. 이러한 리모델링 프로젝트의 공기지연을 야기하는 리스크요인들이 모든 리모델링 프로젝트에 공통적으로 발생하는 것은 아니며, 해당 프로젝트의 다양한 특성에 따라 리스크 요인들의 발생가능성이 영향을 받게 된다. 이러한 맥락에서, 리모델링 프로젝트를 수행한 경험이 있는 29명의 현장관리자들을 대상으로 수행된 신뢰성 있는 설문조사 결과를 바탕으로, (1) 리모델링 프로젝트의 속성들이 리스크 요인의 발생에 얼마나 빈번하게 영향을 미치는지를 평가한 "프로젝트의 속성별 중요도"를 산정하였고, (2) 어떤 리스크 요인의 발생가능성이 가장 큰지를 평가한 "리모델링 사업의 공기지연 리스크 요인별 중요도" 그리고 (3) 이상의 두 가지를 혼합한, "각각의 리스크 요인의 발생에 영향을 미치는 프로젝트 속성별 영향도"를 분석하였다. 본 연구를 통하여, 리모델링을 고려하는 건축물의 다양한 특성들과 공기지연 리스크 발생가능성 사이의 관계를 다각적인 측면으로 분석하였고, 이를 통해, 리모델링을 계획하고 있는 발주자가 해당 프로젝트의 오피스의 특성에 따라 발생가능성이 높은 공기지연 리스크를 사전에 파악할 수 있을 것으로 기대된다.
재건축과 관련한 각종 규제들이 강화됨에 따라 향후 공동주택 리모델링사업이 활발하게 이루어 질 것으로 예상된다. 그러나 공동주택 리모델링사업을 수행할 수 있는 관리시스템의 부재로 사업의 어려움을 가지고 있다. 이에 본 논문에서는 리스크관리에 필요한 리스크 인자를 식별하고 분석하여 AHP에 의한 쌍별비교와 리스크 레벨분석을 위한 확률평가를 시행하여 리스크 수준을 제시하였다. 본 연구가 공동주택 리모델링사업의 리스크를 최소화하고 사업을 원활히 수행할 수 있는 기초자료로 활용되어 건축산업의 기조가 신축위주에서 지속 가능한 산업으로 발전하는데 도움이 되지를 기대한다. 향후 연구과제로 본 연구의 리스크 인자분석의 자료를 활용하여 리스크 관리 모델구축이 있어야 할 것으로 사료된다.
오피스 건축물의 리모델링 사업에서, 신축과는 다른 리모델링 사업의 다양한 리스크로 인해 공기가 지연되는 사례가 빈번하게 보고되고 있다. 이에 본 연구에서는 리모델링 프로젝트의 리스크 요인들과 리모델링 공사의 작업별 공기지연 발생가능성의 관계를 분석하고자 수행되었다. 리모델링 사업의 경험이 있는 29명의 전문가 면담결과의 과학적 통계적 분석을 통해, 리모델링 사업의 리스크 요인과 그로 인한 작업별 공기지연 가능성을 크게 3가지 측면에서 분석하였다. 즉, (i) 리모델링 공사의 작업별 공기지연 가능성, (ii) 리모델링 공사의 리스크 요인별 중요도, (iii) 리모델링 공사의 공기지연에 영향을 미치는 리스크 요인 등 세가지 분석결과를 제시하였다.
Purpose: It is important to note that the relative importance of risk factors should be identified to successfully complete the remodeling project of general hospital. Approached by analytic hierarchy process (AHP), the present study aimed to systematically evaluate the risk factors for remodeling of general hospital. Methods: The present work classified the risk factors of general hospital remodeling into four major categories including the requirements survey stage, planning and design stage, dismantling and construction stage, and maintenance stage. In addition, four sub-categories were derived from each major category factor. Furthermore, five major categories and four subcategories were selected to be considered from the perspectives of two stakeholders of contractor and constructor. The relative importance of the major and sub-categories factors was calculated using the AHP technique on the survey data collected from 49 respondents who participated in the survey study. Results: The results indicate that, the risk factor of requirements survey stage was found to be the most important risk factor to consider among the four major categories of factors. Also, insufficient preliminary investigation, design inconsistencies in architecture/mechanics/electricity, occurrence of safety accidents, and insufficient review of various equipment capacities and performances were found to have the highest priorities of each subcategory factor group included in the four major categories. From the perspective of contractor, the error in predicting the construction period was found to be the most important risk factor. The occurrence of safety accidents during construction was found to be the most important risk factor to be considered by constructor. Implications: The result of the current work should provide important insights and guidelines for the risk management activity that contributes to controlling the project time, cost, and scope required for general hospital remodeling.
건축 리모델링 공사비는 신축과 달리 기존 건축물이 지니는 설계제약여건과 공사환경에 따른 다양한 영향인자들(내구연한, 지반상태, 대지여건 등)에 의해 영향을 받기 마련이다. 이러한 리모델링 사업의 성공적 수행을 위해서는 의사결정과정에서 다양한 불확실성 인자들에 대한 명확한 진단이 필수적이다. 현행 리모델링 비용 견적 프로세스를 살펴보면, 과거 신축 건물의 경험치에 전적으로 의존하고 있을 뿐만 아니라, 불확실성에 입각한 체계적인 평가 방법론이 구축되어 있지 않아서 공사비 증가 등에 따른 사업 리스크가 상존해 있다. 이를 위해서는 리모델링 공사비 견적 시 리스크를 반영한 확률론적 산출 방안의 개발이 요구되고, 이를 위해 리모델링 의사결정 대안별 영향요인의 체계적인 파악을 통해 경험과 직관에 의존하는 기존 방식에서 탈피해야 할 필요가 있다. 본 연구는 공동주택 리모델링 사업의 성공적인 수행에 장애요인으로 작용하고 있는 확정적(deterministic) 견적 산출 방식을 프로젝트의 불확실성을 반영한 확률론적(probabilistic) 견적 방식으로의 전환을 위한 방법론을 구축하였다. 이를 통해 리모델링 사업 초기 개산 견적 시 프로젝트의 특성에 따른 불확실성을 반영한 예상 공사비를 산출함으로써, 발주자의 합리적인 리모델링 투자 의사결정을 지원할 수 있을 것으로 판단된다.
국내 공동주택 시장은 1980년대 이후 급격한 경제성장과 함께 부동산 시장이 활발해 짐에 따라 도시인구의 급격한 증가를 보이며 계속적으로 도시에 공급되어 도시 주거문화의 형태로 자리 잡았다. 하지만 시간이 갈수록 대량 공급 되었던 공동주택은 노후화가 진행되어, 재건축을 통해 환경개선을 이루었다. 그러나 재건축은 진행 과정에서 많은 양의 건설 폐기물을 발생시키며, 도심 환경의 악화, 소음, 교통, 세대수 증가 등이 문제점으로 따라 왔으며, 개발이익 위주로 추진되고 있는 재건축에 문제점들로 인해 각종 규제가 강화되자 공동주택 리모델링이 주목 받기 시작 하였고, 최근 주택법 등이 바뀌기 시작하면서 소규모 중, 고층 공동주택 등을 시작으로 수직증축 리모델링 사업이 추진되었다. 환경개선은 물론 시대적 요구사항에 맞게 변모하고 하였으며, 기존 건물을 사용한다는 점에서 여러 우려와 문제점을 나타내기도 하지만 미래적 방향으로 꼭 필요한 리모델링의 한 분야이다. 이에 본 연구는 공동주택 수직증축 리모델링 시공 사례 분석과 기존 연구 자료를 통해 리스크 발생 요인을 유형별로 조사 하였고, 시공 시행사, 설계 및 전문가로부터 설문조사 와 면담을 통해 관리개선요소 우선순위 분석을 통하여 상대적 중요도를 선정 하였다.
Disasters that occur most frequently in rural areas are drought, flood, damages from wind and cold weather. Among these, damages from storm and flood and drought are the main disasters and recently, these are occurring on a large scale due to unusual weather conditions. Under such circumstances, projects and researches on disasters in rural areas are under way but they are mostly targeting one area or making approaches focusing on repair facilities, maintenance project of facilities in small streams, and disaster management, so there have not been enough studies on the current status of overall damaged facilities in the rural areas. Against this backdrop, through the analysis of the current status of damaged facilities due to storm and flood in rural areas, this study aims to provide base data for policies needed for disaster recovery planning and maintenance work of rural areas. For the analysis of damaged facilities due to storm and flood in rural areas, using the annual report on disasters issued by Ministry of Public Safety and Security and based on the occurrence rate of estimated damage in each city and district for the past 10 years(2004~2013), 8 areas with the highest number of occurrence and cost of damage were found from each province and target areas were selected. Then, regarding the selected target areas, the General Plan for Reducing Damages from Storm and Flood, which is the report on top-level plan for preventing disasters, was secured and the current status of damaged facilities were analyzed. After organizing the analysis of current status, the tendency of damaged facilities due to storm and flood in rural areas, the items of damaged facilities depending on the types of storm and flood damages, and risk factors were suggested. Based on this result, in order to generalize the results of follow-up researches, it is thought that disaster recovery planning and establishing the system of remodeling items necessary for maintenance work would be possible by analyzing damage investigation items recorded in additional researches on rural areas, researches on natural disasters, and recovery plan instructions and by conducting on-site investigation on the damaged villages from storm and flood in rural areas.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.