• 한국건설관리학회논문집
• /
• 제9권5호
• /
• pp.214-226
• /
• 2008

Construction delay caused considerable losses to project parties. Avoiding construction delays is important to save costs for project stakeholders. The main objective of this paper is to identify major causes of construction delays of apartment construction projects in Vietnam. Sixteen causes of delay were identified through a questionnaire survey of 166 professionals. Factor analysis was employed to categorize these causes. The results of the survey revealed the main causes of delay of apartment projects in Vietnam are: (1) owner's and contractor'S financial difficulties; (2) lack of experienced contractors; (3) late delivery of materials; (4) late construction site handover; (5) owner's late payments for completed works; (6) low bid prices; (7) inappropriate construction method; and (8) defective works and unnecessary reworks. Factor analysis uncovered that causes of delay can be grouped under five categories labeled the five INs: incompetence, ineffectiveness, inadequateness, inapplicableness and inconceivableness. Comparative analysis between the Vietnam construction industry (VCI) and the Korea construction industry (KCI) has been performed to infer valuable lessons for researchers and practitioners in the VCI and the KCI. Comparative analysis indicated that main causes of delay in the VCI somewhat differ from main causes of delay in the KCI. However, "contractor'S financial difficulties", "late construction site handover", "unnecessary rework", "incapable designers", "site clearance difficulties" are common causes of delay in the VCI as well as the KCI. The findings of this research can be used as a guideline to overcome problems in the VCI as well as in other construction industries. Since Korea has emerged as the first largest foreign investor in Vietnam, the results of this study may be useful not only to practitioners and researchers in Vietnam but also to participants in Korea.

• Journal of Construction Engineering and Project Management
• /
• 제7권1호
• /
• pp.13-25
• /
• 2017

Construction projects have been observed to have problems of project delays and disruptions and the South African construction industry is not an exception. This research identified causes and effects of project delay and disruption through a desktop study. Subsequently, a questionnaire was designed and used to conduct a survey to obtain the views of the three main construction project participants - clients, consultants, and contractors. The questionnaire contains 48 causes and 13 effects of project delay and disruption identified from the desktop study. This research identified sixteen most important causes of project delay and disruption and five most important effects of delay and disruption. Sixteen most important causes were: (1) strikes, (2) rework due to errors during construction, (3) shortage of materials in market, (4) suspension of work by the client, (5) poor communication between the parties, (6) ineffective planning and scheduling of project, (7) delays in issuing working drawings, (8) mistakes and discrepancies in design documents, (9) shortage of labours and equipment, (10) delay in decision making process by the client, (11) unforeseen ground conditions, (12) unclear and inadequate details in drawing, (13) inadequate contractor's experience, (14) delay in approving changes in the scope of works, (15) delay in material delivery and (16) unacceptable quality of materials. The five major effects include: (1) create stress on contractors, (2) cost overrun, (3) time overrun, (4) poor quality of work due to rush, and (5) disputes. Furthermore, the result of this research was compared with the result of previous studies conducted in other regions of Africa in terms of causes and effects of project delay and disruption. The research concludes that numerous causes and effects of delay and disruption are limited to South African construction projects based on the comparison. The causes limited to South African construction projects include: (1) strikes, (2) suspension of work by the client (3) mistakes and discrepancies in design documents (4) delay in approving changes in the scope of works and (5) unacceptable quality of materials, while the two major effects limited to South African construction projects includes: (1) create stress on contractors and (2) poor quality of work. In conclusion, some recommendations were made in order to minimise the causes of delay and disruption identified.

• 국제학술발표논문집
• /
• The 6th International Conference on Construction Engineering and Project Management
• /
• pp.82-86
• /
• 2015

Construction delay is a common problem worldwide, which is considered as one of the main reasons for project failure. Bangladesh construction industry is no exception. This study investigated the main causes of delay in large building construction projects in Bangladesh. A questionnaire survey was conducted to determine the causes of delay from owners, consultants, and contractors of large building construction projects. About 70 respondents participated in the survey. Using the importance index analysis, the study identified 10 most important causes of delay from a list of 30 different causes. Ten most important causes were: (1) lack of experienced construction manager, (2) lowest bidder selection, (3) funding shortage by owner, (4) lack of proper management, (5) improper planning and scheduling, (6) lack of skilled workers, (7) site constraints, (8) contractors' cash flow problems during construction, (9) escalation of resources price, and (10) contractors' excessive workload. Furthermore, Kruskal-Wallis test indicates that there is no significant variation exists among the three group of respondents, ie owners, consultants and contractors.

• 한국건설관리학회:학술대회논문집
• /
• 한국건설관리학회 2006년도 정기학술발표대회 논문집
• /
• pp.268-270
• /
• 2006

The purpose of this paper was to explore delay avoiding measures and strategies. The paper was based on previous work of authors on finding delay causes. Firstly, the paper has discussed about delay avoidance measures prescribed by the previous work. As the previous study identified five main causes of construction delays, various measures and strategies to overcome those delay problems have been discussed in sequence in the last sections. Major delay prevention strategies are: involving stakeholders in the project decisions, outreach program, realistic time and resource estimation, try to adjust the triple constraints of time, cost and scope, ensure fair and complete disclosure of information at an early stage of the construction project, contractor, itself should inquire about patent design errors prior to submitting its bid, owner should include in its contract with the consultant an indemnity (protection) clause etc.

• Journal of Construction Engineering and Project Management
• /
• 제7권1호
• /
• pp.1-12
• /
• 2017

Construction delay is one of the basic constrains to achieve the project objectives in developing countries. This study aims to find the causes and effects of construction delays in developing countries. A thorough literature review has been done following the content analysis method. The relevant literature of 28 developing countries was collected from the scholarly journals published in the period of 2006 to 2016. The different developing countries are grouped into three geographic regions, i.e. South and Southeast Asia, Middle East, and Africa. In these regions, total 53 potential causes of delay under 8 major groups are identified. Frequency and ranking of these factors have been done. The factors, delay in progress payment by owner, contractors' cash flow problem, improper planning and scheduling, poor site management, and change order by owner during construction, are acknowledged as critical causes of delay in developing countries. This study will assist both academic and professional experts providing more insight about the construction delays and project management in developing countries.

• 국제학술발표논문집
• /
• The 1th International Conference on Construction Engineering and Project Management
• /
• pp.758-763
• /
• 2005

For international projects in general and the projects in the Gulf area in Particular, the most common cause of construction disputes and claims is construction delay. This paper will present different surveys to identify the causes of delay, the parties responsible, and how delay can be avoided. This paper will outline how these factors impact damage assessment and entitlement. Furthermore, a case study will be presented to show how the responsibility and damages due to delay are assessed and how entitlements are calculated.

• Journal of Preventive Medicine and Public Health
• /
• 제26권4호
• /
• pp.650-660
• /
• 1993

This study aims to describe the causes of medically unnecessary hospital stay at a teaching tertiary hospital, using modified version of Delay Tool in which the causes of delay are divided into slx major categories : delay related to test scheduling, test results, surgery, medical staff, patient/family, and administration. For the analysis of hospital stay, 6,479 inpatient-days were reviewed in two medical and four surgical departments for one month. Initially inappropriate hospital stays were identified using Appropriateness Evaluation Protocol (AEP), and causes of delay listed in Delay Tool were assigned to each of them. In both medical and surgical services, the most important cause of delay was related to medical staffs, ranging from 3.6% to 51.6% of total inpatient days. Next important category was delay related to test scheduling in medical services ($4.7{\sim}9.2%$), and delay related to surgery in surgical services ($7.3{\sim}15.0%$). Among subcategories of delay related to medical staffs, delay due to conservative care was the most important cause of inappropriate hospital stay ($2.9{\sim}6.4%$). Each clinical departments had different distribution among delay categories, which could not be fully justified by their clinical charateristics. The Delay Tool would be helpful in exploring factors related to the inefficient use of hospital beds. As a measurement tool of inappropriate hospital stay, however, the Delay Tool should be refined in the definitions of categories and its contents.

• Industrial Engineering and Management Systems
• /
• 제15권4호
• /
• pp.335-344
• /
• 2016

Construction project is a competitive business with high risk especially in developing countries like Iran which faces with many problems such as delay and time and costs increases. Thus, the first priority here is to determine the causes of prolongation of construction projects and to evaluate their importance. Khuzestan Steel Company (KSC) has made important contribution to the projects in Iran and in turn is required to finish them on time. In this study, an attempt was made to investigate the causes of delay in implementation of construction projects held by this company. Data was collected through questionnaire distributed among the sample including 10 owners, 10 consultants and 15 con-tractors. Accordingly, participants rated the causes in the questionnaire so the most important priorities of each area were specified using TOPSIS method. The results showed that according to the employers, consultants and contractors' viewpoints, the most important reason for delays in construction projects of KSC is related to the financial matters. Hence, according to the results obtained, causes for delays in the company's projects are largely related to the drilling permits and long administrative cycle to renew them. Besides, continuous production of steel in this company is another reason to delays of construction projects.

• ETRI Journal
• /
• 제40권3호
• /
• pp.347-354
• /
• 2018

Using various offset times to separate differential services is the most common form of service differentiation in optical burst switching networks. In this approach, a larger offset time is given to a higher priority burst, but it causes this burst to have a longer delay. One solution to this problem is to adjust the burst assembly time so that the buffering delay of the higher priority burst is always shorter than that of the lower priority burst. However, this adjustment causes another problem, called delay unfairness, for bursts with differential priorities that share the same path to their destination. This article proposes a new solution for delay fairness using the burst assembly.

• 한국건축시공학회지
• /
• 제19권5호
• /
• pp.467-475
• /
• 2019

Delay is one of the most critical issues for construction projects and leads to huge losses in both developing and industrialized countries. The construction sector in Rwanda, a rapidly-developing nation, is no exception. Delays can be mitigated only once we have identify their primary causes, and these may not be the same in each region. This study aims to ascertain the main critical factors responsible for delays in building construction in Rwanda through an intensive literature review and questionnaire survey. A total of 40 delay causative factors were obtained from a literature review and were further classified into nine major categories. The questionnaire survey was distributed to about 80 respondents from clients, contractors, and consultants. From the list of 40 different factors, the top twelve most critical causes were identified as stoppage of work due to cash flow constraints, delay in approving design documents, confidentiality of physical plan, price fluctuations and delay in approving significant change, change orders, delay in performing inspections, Ineffective project planning, inadequate drawing details, unqualified labor, lack of materials on the market and dishonesty.