• Journal of Construction Engineering and Project Management
• /
• 제4권3호
• /
• pp.33-46
• /
• 2014

Delay is the most common problem in the construction industry. It has many negative effects on project's success in terms of time, cost, quality, and safety. From the literature review, a total of thirty-five factors of delay were selected. These factors were divided into seven groups related to materials, manpower, owner, consultant, contractor, construction, and external problems. This study was carried out to identify the main causes of delay for a construction project through their importance level. The importance level was determined based on the frequency of occurrence and severity of impact. The structured questionnaire has distributed to the respondents who have much experience in construction management in Bangladesh. The results of analysis indicated that top five factors of construction delay according to their level of importance are: (1) price of construction materials increased very rapidly, (2) political situation (revolution/ public strikes), (3) shortages of skilled workers, (4) poor site management and supervision by contractor, (5) incompetent/ immature subcontractors. These findings of this study are expected to be significant contributions to Bangladesh construction industry in controlling current performance of project on time overrun.

• Journal of Construction Engineering and Project Management
• /
• 제7권1호
• /
• pp.13-25
• /
• 2017

Construction projects have been observed to have problems of project delays and disruptions and the South African construction industry is not an exception. This research identified causes and effects of project delay and disruption through a desktop study. Subsequently, a questionnaire was designed and used to conduct a survey to obtain the views of the three main construction project participants - clients, consultants, and contractors. The questionnaire contains 48 causes and 13 effects of project delay and disruption identified from the desktop study. This research identified sixteen most important causes of project delay and disruption and five most important effects of delay and disruption. Sixteen most important causes were: (1) strikes, (2) rework due to errors during construction, (3) shortage of materials in market, (4) suspension of work by the client, (5) poor communication between the parties, (6) ineffective planning and scheduling of project, (7) delays in issuing working drawings, (8) mistakes and discrepancies in design documents, (9) shortage of labours and equipment, (10) delay in decision making process by the client, (11) unforeseen ground conditions, (12) unclear and inadequate details in drawing, (13) inadequate contractor's experience, (14) delay in approving changes in the scope of works, (15) delay in material delivery and (16) unacceptable quality of materials. The five major effects include: (1) create stress on contractors, (2) cost overrun, (3) time overrun, (4) poor quality of work due to rush, and (5) disputes. Furthermore, the result of this research was compared with the result of previous studies conducted in other regions of Africa in terms of causes and effects of project delay and disruption. The research concludes that numerous causes and effects of delay and disruption are limited to South African construction projects based on the comparison. The causes limited to South African construction projects include: (1) strikes, (2) suspension of work by the client (3) mistakes and discrepancies in design documents (4) delay in approving changes in the scope of works and (5) unacceptable quality of materials, while the two major effects limited to South African construction projects includes: (1) create stress on contractors and (2) poor quality of work. In conclusion, some recommendations were made in order to minimise the causes of delay and disruption identified.

• 국제학술발표논문집
• /
• The 6th International Conference on Construction Engineering and Project Management
• /
• pp.82-86
• /
• 2015

Construction delay is a common problem worldwide, which is considered as one of the main reasons for project failure. Bangladesh construction industry is no exception. This study investigated the main causes of delay in large building construction projects in Bangladesh. A questionnaire survey was conducted to determine the causes of delay from owners, consultants, and contractors of large building construction projects. About 70 respondents participated in the survey. Using the importance index analysis, the study identified 10 most important causes of delay from a list of 30 different causes. Ten most important causes were: (1) lack of experienced construction manager, (2) lowest bidder selection, (3) funding shortage by owner, (4) lack of proper management, (5) improper planning and scheduling, (6) lack of skilled workers, (7) site constraints, (8) contractors' cash flow problems during construction, (9) escalation of resources price, and (10) contractors' excessive workload. Furthermore, Kruskal-Wallis test indicates that there is no significant variation exists among the three group of respondents, ie owners, consultants and contractors.

• 한국건설관리학회논문집
• /
• 제9권5호
• /
• pp.214-226
• /
• 2008

Construction delay caused considerable losses to project parties. Avoiding construction delays is important to save costs for project stakeholders. The main objective of this paper is to identify major causes of construction delays of apartment construction projects in Vietnam. Sixteen causes of delay were identified through a questionnaire survey of 166 professionals. Factor analysis was employed to categorize these causes. The results of the survey revealed the main causes of delay of apartment projects in Vietnam are: (1) owner's and contractor'S financial difficulties; (2) lack of experienced contractors; (3) late delivery of materials; (4) late construction site handover; (5) owner's late payments for completed works; (6) low bid prices; (7) inappropriate construction method; and (8) defective works and unnecessary reworks. Factor analysis uncovered that causes of delay can be grouped under five categories labeled the five INs: incompetence, ineffectiveness, inadequateness, inapplicableness and inconceivableness. Comparative analysis between the Vietnam construction industry (VCI) and the Korea construction industry (KCI) has been performed to infer valuable lessons for researchers and practitioners in the VCI and the KCI. Comparative analysis indicated that main causes of delay in the VCI somewhat differ from main causes of delay in the KCI. However, "contractor'S financial difficulties", "late construction site handover", "unnecessary rework", "incapable designers", "site clearance difficulties" are common causes of delay in the VCI as well as the KCI. The findings of this research can be used as a guideline to overcome problems in the VCI as well as in other construction industries. Since Korea has emerged as the first largest foreign investor in Vietnam, the results of this study may be useful not only to practitioners and researchers in Vietnam but also to participants in Korea.

• 국제학술발표논문집
• /
• The 2th International Conference on Construction Engineering and Project Management
• /
• pp.520-529
• /
• 2007

Apportioning responsibilities of concurrent delay to the owner and the contractor is a difficult task, due to the sophisticate nature both in the schedule and in the factors that cause the delay. This research attempts to develop a simplified yet systematic approach that can be used for a fair apportionment of concurrent delay. A concurrent delay is defined herein as when the contractor and the owner have both caused independent critical path delays during the same approximate time period. Incorporating the concepts of windows analysis and critical path method (CPM), the developed approach has three "windowing of delay" steps to quickly apportion the delay in each of these windows, and a fourth step to sum up those apportioned delays to obtain each party's final responsibilities. This developed approach is found to be simple and effective at this stage; it will be tested against real cases in the near future.

• Journal of Construction Engineering and Project Management
• /
• 제7권1호
• /
• pp.1-12
• /
• 2017

Construction delay is one of the basic constrains to achieve the project objectives in developing countries. This study aims to find the causes and effects of construction delays in developing countries. A thorough literature review has been done following the content analysis method. The relevant literature of 28 developing countries was collected from the scholarly journals published in the period of 2006 to 2016. The different developing countries are grouped into three geographic regions, i.e. South and Southeast Asia, Middle East, and Africa. In these regions, total 53 potential causes of delay under 8 major groups are identified. Frequency and ranking of these factors have been done. The factors, delay in progress payment by owner, contractors' cash flow problem, improper planning and scheduling, poor site management, and change order by owner during construction, are acknowledged as critical causes of delay in developing countries. This study will assist both academic and professional experts providing more insight about the construction delays and project management in developing countries.

• 한국건설관리학회논문집
• /
• 제7권5호
• /
• pp.177-190
• /
• 2006

Construction projects are facing delay problems. Delays in construction have been immense effect on performance or satisfactory delivery of the project. Delays have been causing project cost overrun as well as it is a source of dispute hence damaging the relationship between the project participants. The purpose of this study was to explore the causes of delay risk through a field survey study. Data were collected from construction professionals working in owner, consultant and contractor organizations. All together 208 questionnaire instruments were used and analyzed by employing statistical tools (SPSS computer program). 19 delay factors were identified by this study, out of which following factors were critical: Frequent interruptions from public (local people, pressure group etc.), changed site condition, failure to provide required construction site, unrealistic project time estimation and design errors.

• 한국건축시공학회:학술대회논문집
• /
• 한국건축시공학회 2011년도 춘계 학술논문 발표대회 1부
• /
• pp.191-192
• /
• 2011

The construction projects contain a lot of variables and risk affecting productivity. The duration of the project must be recognized important as for quality, unit cost and safety. There is need for improving work efficiency by investigating relationship of works to prevent delay. This study focuses on analysing the delay factors of steel staircase system to suggest regression model that enables construction productivity estimation. The position of the observers and construction delay factors were expressed by the independent variable of the regression model and productivity was expressed by a dependent variable. This paper suggests quantitative productivity and it is expected that will be helpful estimating application in construction new technologies.

• 한국건축시공학회:학술대회논문집
• /
• 한국건축시공학회 2001년도 학술논문발표회
• /
• pp.93-98
• /
• 2001

If the construction delays are occurred during the project execution, the contractual parties should inquire the delay causes and the contractual obligation. Due to the compensation of damages, the interested parties and the contractual parties are placed on the adverse situation. For reasonable of the claim and dispute, the contractual parties are needed the objective and systematic procedure method to analyze the delay. The purpose of this study is to propose a formal process model considering the case of construction delay-claims.

• 국제학술발표논문집
• /
• The 4th International Conference on Construction Engineering and Project Management Organized by the University of New South Wales
• /
• pp.614-620
• /
• 2011

Delays in completing construction projects have significant financial and social impact to all parties involved in the construction process and in particular in developing countries. This is very evident in most construction projects in Libya and in both public and private sectors. The research study was initiated by Libyan Government and the main aim of the project is to develop a new strategy in reducing the impact of delay factors. In order to achieve this, a number of objectives have been set-to conduct a comprehensive literature survey, to conduct a comparative study of the delay factors in project completion in both Libya and UK using semi structured questionnaire and finally, to identify and analyse the causes of delay and ranked them using frequency of occurrence and severity. The critical causes of delay for construction projects were quite different between Libya and UK. For the former, the most critical causes of delay in Libyan construction industry were low skills of manpower, changes in the scope of the project, slowness in giving instruction and poor qualification of consultant, while for the latter they were financial problems, bad weather conditions on the job site and change in the scope of project. Statistical experiments including Paired Samples T-Test, was run to test the significance of the survey data in both countries Libya and UK. The statistical results confirmed the collected data from the survey were significant.